The Contractor shall perform the following described work at [Insert description/address of property where work is to be done] (the "Property"), in accordance with Owner’s Contract plans and specifications, this Agreement and any Change Order, as defined herein, [Insert description of work to be performed] (the "Work").
The Owner agrees to pay the Contractor the total amount of [Insert amount and currency] (the “Contract Price”). Payment of this amount is subject to additions or deductions in accordance with any mutually agreed to changes and/or modifications in the work. Payment can be made by [cash/check/money order/credit or debit card/wire transfer/other] Payment can also be made in Installments upon completion of different milestones as agreed by both the Owner and the Contractor. The following schedule can be followed for Installments:
Installments will be paid upon the completion of the following milestones:
The Contractor shall provide and pay for all labor and equipment, including tools, construction equipment, machinery, transportation and all other facilities and services, and all materials necessary for the completion of the work. All materials shall be good quality and new, unless the Contract documents require or permit otherwise. The Contractor may substitute materials only with the prior written approval of the Owner.
The Parties shall obtain all licenses and permits necessary for proper completion of the work. Each Party is responsible for the cost of any necessary permits or licenses.
The Contractor shall perform the work in a workmanlike manner and in compliance with all applicable federal, state, and local laws, regulations and ordinances, trade standards, ethical guidelines and any safety requirements of the Owner (the “Applicable Laws”). The Contractor shall promptly notify the Owner upon discovery of any variance between the Applicable Laws and the Construction Documents.
The Contractor shall be solely responsible for and shall supervise and direct all construction under this Contract. The Contractor shall provide competent and suitable personnel to perform the work and shall at all times maintain good discipline and order at the Property. The Contractor will at all times take all reasonable precautions for the safety of its employees and the public at the Property. The Contractor agrees to assume full responsibility for the acts, negligence, and/or omissions of its employees and any subcontractors and their employees.
The [Contractor/Owner] shall pay for all permanent electric, water, phone, cable, sewer and gas service as needed to perform the work. The [Contractor/Owner] shall pay for the installation, connection and removal of all temporary utilities on the Property during the performance of the work. All temporary utilities shall confirm and adhere to the Applicable Laws.
Except as otherwise provided in the Contract Documents, the Contractor shall be responsible for all Hazardous Materials brought to the Property by the Contractor. Hazardous Materials shall include radioactive materials, asbestos, polychlorinated biphenyls, petroleum products, crude oil, flammable materials, chemicals or solvents known to cause cancer or reproductive toxicity, pollutants, contaminants and toxic substances which are restricted, prohibited or regulated by any agency of government in its manufacture, use, maintenance, storage, ownership or handling.
If the Contractor discovers any Hazardous Materials on the Property, the Contractor shall immediately notify the Owner and may cease working until the material or substance has been rendered harmless. The Owner shall defend, indemnify and hold harmless the Contractor, any subcontractors, and their respective agents and employees from and against all claims, damages, losses and expenses, including attorney’s fees, arising out of or resulting from contact with the Hazardous Substance in performance of the work resulting in bodily injury, illness or death, or injury or property damage, provided such claim, damage, loss or expense is not the result of any negligent act or omission by the Party seeking such indemnity.
The Contractor warrants that the work shall be in accordance with the Contract Documents, Applicable Law and Trade Standards and free from material structural defects, improper workmanship or defective materials. The Contractor shall replace, correct or repair any work not in accordance with the Contract Documents, Applicable Law and Trade Standards or any defects caused by faulty materials, equipment or workmanship for a period of [Insert time period in years/months] from the date of completion of the work.
The Owner shall have a right to inspect the work at any time and request that the Contractor promptly correct any work that is defective or does not conform to the Contract Documents. If required, the work shall be inspected and certified by the appropriate state or local agency or health officer at each necessary stage.
If the Contractor fails to correct any defective work or repeatedly fails to perform the work in accordance with the Contract Documents, the Owner shall have the right to order the Contractor to stop performing the work, or any portion thereof, until the cause for such order is eliminated.
The Contractor shall furnish to the Owner a list of names of subcontractors proposed to perform principal portions of the work. The Contractor shall not employ any subcontractor to whom the Owner reasonably objects. A subcontractor, for the purposes of this Contract, shall be a person with whom the Contractor has a direct contract for work at the Property. All contracts between the Contractor and subcontractor shall be in accordance with the terms of this Contract and the Contract Documents.
The Owner reserves the right to order changes to the work in the nature of additions, deletions or modifications, without invalidating this Contract, and agrees to make corresponding adjustments in the Contract Price and Time of Termination if applicable. All changes will be authorized in a written “Change Order” signed by the Owner and the Contractor, which shall be incorporated by reference herein.
The Contractor agrees to defend, indemnify and hold harmless the Owner and its agents and employees, from and against all claims, actions, liabilities, suits, demands, injuries, obligations, damages, losses, settlements, judgments, fines, penalties, costs and expenses, including reasonable attorneys' fees, arising out of any negligent act or omission by the Contractor, a subcontractor or anyone directly or indirectly employed by them in the performance of the work resulting in bodily injury, illness or death, or for property damage, including loss of use, unless caused by the sole negligence or willful misconduct of the Owner.
The Contractor agrees to maintain at its own expense during the entire period of Construction at the Property:
The Contractor shall name the Owner as an additional insured (except for the workers' compensation insurance). Proof of such insurance shall be filed by the Contractor with the Owner within a reasonable time after execution of this Contract.
The Owner and the Contractor each waive any and all claims or rights to recovery against the other Party for any loss or damage to the extent such loss or damage is covered by insurance or would be covered by any insurance required under this Contract. The Owner and the Contractor shall cause each insurance policy carried by the Owner or the Contractor relating to the Property to include or allow a full waiver of any subrogation claims.
All times stated in this Contract or in the Contract Documents are of the Essence. The Contractor agrees that such times are reasonable for performing and completing the work.
The Owner is entitled to damages. In the event the work is not completed by the date set forth in this Contract, plus any extensions thereof as allowed in this Contract, the Owner shall suffer damages uncertain in amount and difficult to measure and prove accurately. The Owner and the Contractor agree that in lieu of actual damages, and not as a penalty, for delay in the performance of the work, the Contractor shall pay the Owner the sum of [Insert amount] for each calendar day completion of the work is delayed. The Contractor agrees that the liquidated damages specified herein are reasonable in amount and are not disproportionate to actual anticipated damages. The Owner shall have the right to deduct any liquidated damages from any amount due or that may become due to the Contractor. Liquidated damages shall be the sole and exclusive remedy for the Owner for delay in completion of the work past the agreed upon date.
The time stated in this Contract may be extended for such reasonable time as the Contractor may determine when performance of the work by the Contractor is delayed by a Change Order, labor disputes, fire, unusual delay in deliveries, abnormal adverse weather conditions, unavoidable casualties, or other causes beyond the Contractor’s control or which justify the delay.
Any dispute arising from this Contract shall be resolved through:
Work under this Contract shall begin on [Insert beginning date] and shall be completed by [Insert completion date]. Upon completion of the Work, the Contractor shall notify the Owner that the work is ready for final inspection and acceptance and the Owner shall make the final payment within [Insert number of days] days after final inspection.
This Contract may be executed in one or more counterparts, each of which shall be deemed an original and all of which together, shall constitute one and the same document.
The section headings herein are for reference purposes only and shall not otherwise affect the meaning, construction or interpretation of any provision of this Contract.
Any notice or communication given or made to any Party under this Contract shall be in writing and delivered by hand, sent by overnight courier service or sent by certified or registered mail, return receipt requested, to the address stated above or to another address as that Party may subsequently designate by notice and shall be deemed given on the date of delivery.
No Party hereto shall have the right to assign its rights or delegate its duties hereunder without the written consent of the other Party.
This Contract shall be binding and ensure to the benefit of the Parties and their respective legal representatives, heirs, administrators, executors, successors and permitted assigns.
This Contract and the rights and obligations of the Parties hereto shall be governed by and construed in accordance with the laws of [Insert name of state or country].
If any provision of this Contract is held to be invalid, illegal or unenforceable in whole or in part, the remaining provisions shall not be affected and shall continue to be valid, legal and enforceable as though the invalid, illegal or unenforceable part had not been included in this Contract.
This Contract may not be amended or modified except by a written agreement signed by all of the Parties.
No Party shall be deemed to have waived any provision of this contract or the exercise of any rights held under this contract unless such waiver is made expressly and in writing. Waiver by any Party of a breach or violation of any provision of this Contract shall not constitute a waiver of any other subsequent breach or violation.
The Contractor acknowledges that it is an independent contractor and is not an agent, partner, joint venture nor employee of the Owner. The Contractor shall have no authority to bind or otherwise obligate the Owner in any manner nor shall the Contractor represent to anyone that it has the right to do so.
Nothing in this Contract shall create or give to any third party a claim or right of action against the Contractor or the Owner.
As a result of the Contractor's participation in the work, the Contractor will have access and contribute to information and materials of a highly sensitive nature, including Confidential Information. The Contractor hereby warrants that the Contractor and its employees and agents shall not (without in each instance obtaining the Owner's prior written consent) disclose, make commercial or other use of, or give or sell to any person, firm, or corporation, any Confidential Information received directly or indirectly from the Owner or acquired or developed in the course of the performance of this Contract unless:
This Contract contains the entire agreement between the Parties hereto with respect to the subject matter hereof, and supersedes all prior negotiations, understandings and agreements.
The Contractor shall maintain in a safe place at the Property one record copy of all drawings, specifications, addenda, written amendments, and the like in good order and annotated to show all changes made during construction, which will be delivered to the Owner upon completion of the work. The Owner shall have the right to inspect and review such documents upon notice to the Contractor.
Show the full contractDisclaimer: Template does not constitute any form of legal advice, and the User is at all times encouraged to request external specific legal advice in respect of the execution of legal documents.
Construction contractConstruction contracts set out the terms of an upcoming construction project. Access our free template to build a solid foundation.
Used 0 times Ready to sign and send Dynamic Data FieldsFill it up smartly and sign digitally. Make your contracts dynamic, so you can analyze, decide and act quicker.
Tame your chaos with a central place to store and manage contracts, so you can analyze, decide and act quicker.
A construction contract is the blueprint for any building or renovation project. When a client wants to bring their vision to life, they hire a general contractor who, in turn, oversees the entire project. This agreement outlines what the general contractor will do, how much they'll get paid, and any conditions they must meet.
Plus, it covers essential details like subcontracting rights and necessary permits, leaving no stone unturned in the building process.
Generally, it also includes a timeline by which certain parts of the job should be completed. It may also include information such as when payment can be requested. A clearly written construction contract can save the parties involved a lot of hassle and money since the responsibilities and timeline are documented within the contract.
A construction contract could be used for a home or business. Depending on the client, a construction contract will contain different information. For example, a residential contract will contain various information from a commercial construction contract.
A lump sum contract is the most common pricing arrangement for construction contracts. It is also known as a “fixed price” contract. In a lump sum contract, the parties agree to one price based on the contractor’s estimate of the project's total costs. A lump sum contract includes all the materials, labor, subcontracts, profit, and all other related expenses. Lump sum contracts can include incentives for early termination and penalties for late termination.
Lump sum contracts are used when the owner wants to transfer risk to the builder and avoid change orders for unspecified work.
A cost-plus contract is an agreement for the owner to pay for all the costs associated with a construction project plus an additional fixed fee for a profit margin. This means the owner will first pay for all the expenses incurred during construction, such as materials and labor. The owner will then pay the contractor an additional agreed-upon fee, usually a flat fee or a fixed percentage based on a percentage of the total costs.
Cost-plus contracts are used when the scope of work is not clearly defined. The owner is responsible for establishing limits on how much a contractor bills.
In a unit-price construction contract, the parties set a price for every unit of work. A unit price contract can be based on hours, linear feet, cubic yards, or by item.
Federal agencies often use unit price contracts. These contracts allow an owner to set prices during bidding by requesting specific quantities and pricing for a set number of items.
Time and material contracts are used when parties agree to pay a predetermined rate for a unit. These contracts are used when it is impossible to present an accurate estimate or when it is difficult to define a schedule. A time and materials contract is the riskiest contract for the owner and the most secure kind of contract for the contractor.
A time and materials contract should specify labor costs, material markup, not-to-exceed or maximum amount charged, and maximum labor hours.
Contractbook simplifies the complex process of finalizing agreements in the construction industry. Its intuitive platform allows users to effortlessly draft, customize, and send contracts to all parties involved.
Everyone from general contractors to subcontractors and clients can quickly review and sign documents online, eliminating the need for cumbersome paperwork and manual signatures. Plus, Contractbook's secure digital signatures ensure legal compliance and peace of mind, streamlining the entire contract management process for construction projects of any scale.
